Terms & Conditions

Effective Date: January 1, 2026 | Last Updated: August 2026

1. Acceptance of Terms

By accessing this website (https://digiritwick.online/) or commissioning Digiritwick ("Company", "we", "us") to perform web design, software development, SEO, or digital marketing services, you ("Client", "you") agree to be bound by these Terms and Conditions. If you do not accept these terms, you must refrain from using our services.

2. Scope of Services

Digiritwick provides professional IT engineering and digital growth services including Website Design & UI/UX, Custom Web Development, Enterprise Software Engineering (SaaS/ERP), Mobile App Development, Search Engine Optimization (SEO), and Digital Marketing. All project scopes, deliverables, and timelines are formally defined in official written project proposals, statements of work (SOW), or invoices.

3. Payments & Billing Terms

• Deposit & Milestones: Unless otherwise agreed in writing, a 50% deposit is required before project initiation, with remaining milestone payments due upon completion of designated project phases.
• Invoice Due Dates: Invoices issued by Digiritwick are due within 14 calendar days from the invoice date. Late payments exceeding 30 days may incur a 2% monthly late fee and temporary suspension of active server work or deployment.
• Final Deployment: Live server deployment, source code transfer, or domain DNS pointing will occur only after receipt of 100% full final project payment.

4. Client Responsibilities & Asset Submissions

The Client agrees to provide all necessary text content, high-resolution logos, product images, and third-party API credentials required to complete the project within 5 business days of request. Delays in client assets or approval feedback will extend the agreed project delivery timeline accordingly.

5. Intellectual Property Rights & Code Ownership

Upon receipt of 100% full payment, Digiritwick transfers all intellectual property rights and full ownership of the custom code, database structures, and visual design assets developed specifically for the project to the Client. Digiritwick retains ownership of pre-existing core code frameworks, reusable developer libraries, and the right to display completed project screenshots in our agency portfolio.

6. Revisions & Scope Changes

Each project estimate includes up to two (2) rounds of minor revisions during the design and development review stages. Any significant feature requests, structural alterations, or new functional requirements outside the original SOW will be treated as Change Orders and billed at Digiritwick's standard hourly rate or custom milestone fee.

7. Post-Launch Warranty & Maintenance

Digiritwick provides a 30-day bug-fix warranty post-launch for all custom web and software projects to resolve any code errors or functional bugs directly attributable to original development. Modifications made by third parties, server environment changes, or requests outside the SOW post-launch require a separate Service Level Agreement (SLA) maintenance contract.

8. Limitation of Liability

To the maximum extent permitted by applicable law, Digiritwick shall not be liable for any indirect, incidental, special, or consequential damages, loss of business revenue, or server downtime resulting from third-party hosting failures, domain registry interruptions, or unauthorized external hacking attempts. Our total aggregate liability under any circumstances shall be limited to the total fees paid by the Client to Digiritwick for the specific service rendered.

9. Termination

Either party may terminate a project agreement by delivering 7 days written notice. In the event of early termination, the Client shall pay Digiritwick pro-rata for all billable hours and work completed up to the date of termination.

10. Governing Law & Jurisdiction

These Terms and Conditions shall be governed by and construed in accordance with the laws of India. Any legal disputes or claims arising out of or in connection with Digiritwick's services shall be subject to the exclusive jurisdiction of the Courts of Delhi, India.

11. Contact Information

For questions regarding these Terms & Conditions or official project contracts, please contact our management team: